Photo of Steve McBradyPhoto of John Nakoneczny

At midnight on October 1, 2024, the International Longshoremen’s Association launched a labor strike that effectively shut down all ports from Maine to Texas after being unable to reach agreement on terms for a new labor contract with the United States Maritime Alliance.  This strike may impact virtually all industries that rely on maritime shipping, either directly or indirectly. 

Government contractors should be cognizant of their rights since shipping delays resulting from the strike could affect their performance.  If a contract incorporates FAR 52.249-14, Excusable Delays, or one of the FAR Default clauses, such as FAR 52.249-8, Default (Fixed-Price Supply and Service), then delays that are attributable to the dockworkers’ strike should be excusable, and contract performance times extended.  However, if the delay is attributable to a subcontractor whose performance is impacted by the dockworkers’ strike, then a prime contractor may need to consider the possibility of procuring supplies from an alternative supplier.  Contractors should use their best efforts to timely notify their respective contracting officers of any performance impacts and request additional time to perform, as well as document any directions they receive from the contracting officer.

The FAR’s Excusable Delay clause and the Default clauses do not address monetary relief for excusable delays.  However, certain circumstances may change the calculus, such as where the government does not grant extensions when appropriate, or when certain warranties made by the government were breached as a result of the strike.  Thus, it is important to provide notice to the government in the event of delays caused by the strike, and it is worthwhile in any notice of impact to the government to reserve the right to seek an equitable adjustment for cost and schedule impacts, as applicable.

Print:
Email this postTweet this postLike this postShare this post on LinkedIn
Photo of Steve McBrady Steve McBrady

Steve McBrady is a partner and co-chair of Crowell & Moring’s Government Contracts Group. He also serves as a member of the firm’s Finance and Strategic Growth Committees, where he has played a leading role in expanding client service offerings throughout the U.S.…

Steve McBrady is a partner and co-chair of Crowell & Moring’s Government Contracts Group. He also serves as a member of the firm’s Finance and Strategic Growth Committees, where he has played a leading role in expanding client service offerings throughout the U.S., Europe, Asia, and the Middle East.

In recent years, Steve has received the National Law Journal’s “Winning Litigator” award as a lawyer who has “tackled some of the most widely watched cases of the year,” as well as the “D.C. Trailblazer” award, recognizing lawyers who have “made significant marks on the practice.” In 2018, he was named “Government Contracts MVP” by Law360.

Photo of John Nakoneczny John Nakoneczny

John Nakoneczny is an associate in the Government Contracts Group in Crowell & Moring’s Washington, D.C. office.

John represents and counsels contractors from diverse industries on contract disputes and other government contract matters. Prior to joining Crowell & Moring, he clerked at the…

John Nakoneczny is an associate in the Government Contracts Group in Crowell & Moring’s Washington, D.C. office.

John represents and counsels contractors from diverse industries on contract disputes and other government contract matters. Prior to joining Crowell & Moring, he clerked at the Civilian Board of Contract Appeals, where he supported its judges in resolving and mediating appeals under the Contract Disputes Act. John earned his J.D. from The George Washington University Law School, where he was the president of the Government Contracts Student Association and on the Federal Circuit Bar Journal. While in law school, John served as a legal intern at the U.S. General Services Administration and the Fraud Section of the U.S. Department of Justice, Criminal Division. Upon graduation, John was awarded the President’s Volunteer Service Award.