The Federal Circuit recently affirmed the Civilian Board of Contract Appeals’ (CBCA) decision denying a pandemic-related claim in Pernix Serka Joint Venture v. Secretary of State, CBCA No. 5683, 20-1 BCA ¶ 37,589.  Pernix involved a firm-fixed-price construction contract in Sierra Leone that was impacted by an Ebola outbreak several months into the project.  The Department of State (DOS) declined to provide direction or to issue a suspension of work order, and instead advised Pernix to make its own business decisions regarding performance and employee safety.  Pernix chose to demobilize its workforce and, later, to remobilize with the addition of its own on-site medical facility and services.  Pernix then submitted a claim for the increased medical, safety, and demobilization and remobilization costs.  DOS granted an adjustment to the schedule for the Ebola-related delays under the contract’s excusable delay clause, but denied Pernix’s monetary claim.
Continue Reading Federal Circuit Affirms Board Decision on Pandemic-Related Claim