Photo of Steve McBradyPhoto of Brian Tully McLaughlin

In EM Logging v. Department of Agriculture, 2014-1227 (Feb. 20, 2015), the Federal Circuit reversed the Civilian Board of Contract Appeals, holding that substantial evidence did not support the Board’s conclusion that the US Forest Service had properly terminated a timber sale contract for the Kootenai National Forest in Northern Montana for “flagrant disregard” of the terms of the contract.  On appeal, the court found that the record supported only four instances of route deviation, load limit violations, or delayed notifications, and held that the contractor’s actions did not justify termination because termination for “flagrant disregard” must be “predicated on more than technical breaches of minor contract provisions or isolated breaches of material contract provisions which caused no damage.”

Print:
Email this postTweet this postLike this postShare this post on LinkedIn
Photo of Brian Tully McLaughlin Brian Tully McLaughlin

Brian Tully McLaughlin is a partner in the Government Contracts Group in Washington, D.C. and co-chair of the False Claims Act Practice. Tully’s practice focuses on False Claims Act investigations and litigation, particularly trial and appellate work, as well as litigation of a…

Brian Tully McLaughlin is a partner in the Government Contracts Group in Washington, D.C. and co-chair of the False Claims Act Practice. Tully’s practice focuses on False Claims Act investigations and litigation, particularly trial and appellate work, as well as litigation of a variety of complex claims, disputes, and recovery matters. Tully’s False Claims Act experience spans procurement fraud, healthcare fraud, defense industry fraud, and more. He conducts internal investigations and represents clients in government investigations who are facing fraud or False Claims Act allegations. Tully has successfully litigated False Claims Act cases through trial and appeal, both those brought by whistleblowers / qui tam relators and the Department of Justice alike. He also focuses on affirmative claims recovery matters, analyzing potential claims and changes, counseling clients, and representing government contractors, including subcontractors, in claims and disputes proceedings before administrative boards of contract appeals and the Court of Federal Claims, as well as in international arbitration. His claims recovery experience includes unprecedented damages and fee awards. Tully has appeared and tried cases before judges and juries in federal district courts, state courts, and administrative boards of contract appeals, and he has argued successful appeals before the D.C. Circuit, the Federal Circuit, and the Fourth and Seventh Circuits.